10.0201 Short title. The rules codified in this chapter shall be known and cited as “American Samoa Procurement Rules.” History: Rule 5-84, eff 11 Jul 84, (part).

10.0202 Authority. The rules in this chapter are promulgated pursuant to the authority granted under Section 12.0214 ASCA. History: Rule 5-84, eff 11 Jul 84, (part).

10.0203 Purpose. The purpose of this chapter is to prescribe uniform rules necessary to fully implement Chapter 12.02 ASCA. History: Rule 5-84, eff 11 Jul 84, (part).

10.0204 Definitions. As used in this chapter, the words in this section shall have the following meanings unless the context otherwise requires:

(a) “Chief procurement officer” means the head of the central procurement office of the government.

(b) “Construction” means the process of building, altering, repairing, improving, or demolishing of a public structure or building, or public improvements commonly known as “capital improvements”. It does not include the routine maintenance of existing structures, buildings, or public real property.

(d) “Contractor” means a person having a contract with an authorizing agency.

(e) “Employee” means an individual receiving a salary from the government, including elective officials and non-salaried individuals performing personal services for the government.

(f) “Goods” means all property, including but not limited to equipment, materials, supplies, and other tangible personal property of any kind or nature, printing, insurance, leases of real and personal property, and sale or other disposal of real and personal property of any kind or nature.

(g) “Government” means the American Samoa Government (ASG) which includes the executive, legislative, and judicial branches.

(h) “Governmental body” means any department, office, agency, or other establishment or official of the government.

(i) “Governor” means the Governor of American Samoa.

(j) “Grant” means the furnishing by the government of assistance whether financial or otherwise to any person to support a program authorized by law.

(k) “Request for Proposals” means all documents, whether attached or incorporated by reference, utilized for soliciting bids.

(l) “Person” means an individual, sole proprietorship, partnership, joint venture, corporation, other unincorporated association, or a private legal entity.

(m) “Procurement” means buying, purchasing, renting, leasing or acquiring construction, goods, or services. It also includes all functions that pertain to the obtaining of construction, goods, or services, including description of requirements, selection and solicitation of sources, preparation and award of contracts and all phases of contract administration. It does not include employment contracts with the individuals to be supervised by ASG employees.

(n) “Rules” mean rules which have been adopted under authority of this chapter in accordance with the provisions of the Administrative Procedure Act, Section 4.1001, ASCA, et seq.

(o) “Reasonable”, in reference to a bidder, means a person whose bid is equitable, fair, and suitable, and is not excessive or inappropriate in any material respect.

(p) “Responsible” in reference to a bidder, means a person who has the capability in all respects to perform fully the contract requirements, and the integrity and reliability which will assure good faith performance.

(q) “Responsive," in reference to a bidder, means a person who has submitted a bid which conforms in all material respects to the Request for Proposals.

(r) “Services” means the furnishing of time, labor, or effort by a person other than an employee, and not involving the delivery of a specific end product other than reports, plans, and incidental documents. History: Rule 5-84, eff 11 Jul 84, (part).

10.0205 Requirement of Good Faith. This chapter requires all parties involved in the negotiation, execution, performance, or administration of government contracts to act in good faith. History: Rule 5-84, eff 11 Jul 84, (part).

10.0206 Applicability.

(a) Except as otherwise specified by law this chapter applies to every expenditure of pubic funds including federal assistance monies and enterprise funds under any contract. This chapter also applies to the disposal of territorial goods.

(b) This chapter does not apply to either grants by the government or contracts between the government and its bodies, political subdivisions, or other governments.

(c) This chapter may not prevent any governmental body or political subdivisions from complying with the terms and conditions of any grant, gift, bequest, or cooperative agreement except that no such agreement shall be used to authorize sole-source procurement or violation of Part X of this Chapter.

(d) Where there is a discrepancy between the provisions of this Chapter and the laws of the territory, the laws shall have precedence over these rules. These rules shall have precedence over executive orders or other executive branch issuances until this Chapter is amended. History: Rule 5-84, eff 11 Jul 84, (part).

II. PROCUREMENT ORGANIZATION

10.0210 Centralization of Procurement authority. Except as otherwise provided by law or executive order, all rights, powers, duties and authority relating to the procurement of construction, goods, and services, and the management, control, warehousing, sale and disposal of construction, goods and services, now vested in, or exercised by a governmental body are transferred to the chief procurement officer. History: Rule 5-84, eff 11 Jul 84, (part).

10.0211 Chief Procurement Officer.

(a) Location. The chief procurement officer shall head the office of procurement in the department of Administrative Services. The office of procurement shall consist of a contract branch, a property management branch, and a policy and review branch.

(b) Appointment and qualifications. The Governor shall appoint and the Legislature shall confirm the chief procurement officer. The chief procurement officer shall meet the qualifications set forth in Section 12.0206 ASCA.

(c) Tenure and removal. The chief procurement officer shall be a full time public official who serves at the Governor’s pleasure.

(d) Authority and duties. The chief procurement officer shall serve as the central procurement official of the government and is authorized to:

(1) Adopt operational procedures or rules governing the internal functions of his office.

(2) Adopt and maintain rules for the government as necessary and appropriate for the implementation of Chapter 12.02 ASCA governing the procurement, management, control and disposal of all construction, goods, and services procured by a governmental body. A separate manual of all rules and amendments to the rules shall be open to inspection and copying during normal business hours.

(3) Except as otherwise specifically provided in this chapter, in accordance with rules adopted.

(a) Procure or supervise procurement of all construction, goods, and services needed by the government;

(b) Exercise general supervision and control over all inventories of goods belonging to the government;

(c) Sell, trade, or otherwise dispose of goods, surplus to the government, and serve as the head of the American Samoa agency for Surplus Property responsible for acquiring surplus federal property under the Federal Property and Administrative Services Act, as amended; and

(d) Established and maintain programs for the inspection, testing and acceptance of construction, goods, and services;

(4) Assist in providing technical assistance, including training, necessary to ensure uniform implementation of the rules in this chapter.

(5) Supervise the conduct of management reviews to monitor compliance with the rules in this chapter and initiate corrective action, as required. History: Rule 5-84, eff 11 Jul 84, (part).

10.0212 Decentralized procurement authority.

(a) Delegation of authority. The chief procurement officer may delegate authority to execute and administer contracts to a procure officer who is responsible for administering procurement on behalf of an agency or governmental body under the provisions of this chapter. The chief procurement officer may delegate authority to supervise and control inventories belonging to the government. The chief procurement officer may also suspend, limit, or revoke any delegation of authority made under provisions of this subsection. Except as otherwise specifically provided in this chapter, the following officials are delegated authority to execute and administer contracts, and control inventories of government property under the conditions prescribed:

(1) Director of Health. Execution and administration of purchase orders and contracts for routine procurement of drugs, medicines, and medical supplies and control of stores of medical supplies.

(2) Director of Public Works. Execution and administration of architect, engineer and construction contracts and control of stores necessary for day-to-day maintenance requirements.

(b) Procurement authority by law or executive order.

(1) Executive Director of the American Samoa Power Authority. Execution and administration of purchase orders and contracts for the Authority and control of stores necessary of day-to-day operations for the Authority pursuant to 15.01 ASCA et seq.

(2) Director of the Marine Railway Authority. Execution and administration of purchase orders and contracts for the Authority and control of stores necessary for day to day operation of the Authority pursuant Executive Order No. 3-1978.

(3) Director of the Department of Agriculture. Control of storage and distribution of fungicides, herbicides, insecticides, weedicides, other agricultural chemicals, and animal feeds and fertilizers pursuant to 24.1201 ASCA, et seq., and 24.2101 ASCA, et seq.

(c) Notification of delegations. Every official having procurement authority by delegation under this section or by law or executive order shall notify the chief

procurement officer in writing of the name of title of any individual to whom that authority is delegated and the scope of the delegated authority. History: Rule 5-84, eff 11 Jul 84, (part).

10.0213 Coordination. Under procedures adopted by the chief procurement officer, and except when a special evaluation or selection group is appointed by competent authority the CIP (Capital Improvement Project) and Procurement Review Committee, shall review and approve the procurement of all construction and of goods and services which exceed $25,000 prior to execution of contracts. The committee may also review contracts of lesser value at its discretion. History: Rule 5-84, eff 11 Jul 84, (part).

10.0214 Duties of the Attorney General.

(a) The Attorney General, or such officer as the Attorney General may designate, shall serve as legal counsel and provide legal services to the chief procurement officer.

(b) The Attorney General shall approve all government contracts exceeding $10,000 as to legal sufficiency prior to execution, regardless of the authority for execution and administration. History: Rule 5-84, eff 11 Jul 84, (part).

III. PROCUREMENT INITIATION

10.0220 Duties of the chief procurement officer. The chief procurement officer shall develop, issue and maintain procedures governing the preparation and initiation of requisitions for the purchase of construction, goods, and services by the government. History: Rule 5-84, eff 11 Jul 84, (part).

10.0221 Duties of the Director of Program Planning and Budget Development. The Director of Program Planning and Budget Development shall certify as to the availability of funding for all requisitions involving the expenditure of public funds, irrespective of source, within 48 hours after receipt of the requisition.

(a) It shall be the policy of the government to identify in advance, to the extent feasible, planned purchases and procurement actions for each fiscal year to:

(1) Avoid the purchase of unnecessary or duplicative goods or services;

(2) Consider consolidating or breaking out procurement requirements to obtain a more economical purchase;

(3) Consider lease versus purchase alternatives to determine the most economical approaches; and

(4) Insure adequate resources are available and sufficient time is allotted to insure delivery of needed goods and services.

(b) The head of each governmental body initiating requisitions shall submit to the chief procurement officer, by October 1 of each year, a list of purchases planned for the fiscal year (other than small purchases) including:

(1) A description of the purchase;

(2) Estimated dollar amount;

(3) Required delivery date; and

(4) Estimated date for requisition initiation.

(c) The list of planned purchases shall be updated on a quarterly basis by the head of each governmental body initiating requisitions. History: Rule 5-84, eff 11 Jul 84, (part).

IV. SOURCE SELECTION AND CONTRACT FORMULATION

10.0230 Definitions. As used in this article, the following definitions shall apply:

(a) “Bidding time” means the time between the issuance of a solicitation and the opening of bids or the due date for proposal.

(b) “Cost-reimbursed for contract” means a contract under which a contractor is reimbursed for costs which are allowable and allocable in accordance with the contract terms and a fee, if any.

(c) “Firm-fixed-priced contract” means a contract under which a contractor agrees to perform the work required for a price which is not subject to any adjustment.

(d) “Offer or” means a person who has submitted a proposal in response to a request for proposal.

(e) “Purchase description” means the words used in a solicitation to describe the construction, goods, or services to be procured.

(f) “Request for Proposals” means all documents utilized for soliciting proposal under the negotiation method of procurement. History: Rule 5-84, eff 11 Jul 84, (part).

10.0231 Methods of source selection.

(a) It is the policy of the government to conduct all purchases and procurement actions in a manner that provides maximum open and free competition.

(b) Unless otherwise authorized by law, all government contracts shall be executed by competitive sealed bidding, in accordance with Subsection 10.0231, except as provided in:

(1) Subsection 10.0231 (c) for small purchases;

(2) Subsection 10.0231 (e) for negotiation; or

(3) Subsection 10.0231 (f) for emergency procurements.

(c) Small purchases. Any procurement not exceeding $10,000 including purchases made using impress funds shall be made using simplified small purchase procedures promulgated by the chief procurement officer. Procurement requirements may not be artificially divided so as to constitute a small purchase under this subsection and circumvent other source selection rules required under this section.

(d) Competitive sealed bidding.

(1) Conditions for use. Contracts shall be awarded by competitive sealed bidding except as provided in 10.0231(b). For this method to be used, the following conditions shall be present.

(a) A clear, complete, accurate, and realistic purchase description or specification for the good or service to be procured is available;

(b) The purchase description or specification does not contain unnecessarily restrictive requirements or features which may unduly limit the number of bidders;

(d) The procurement requirements can be defined with sufficient accuracy so that a firm-fixed price contract can be executed, and selection of the successful bidder can be made principally on the basis of price.

(2) Invitation for Bids. An invitation for bids shall be issued and shall include:

(a)Request for Proposals number.

(b Date of issuance.

(d) Date, hour, and place of bid opening.

(e) A purchase description and/or specification for the goods or services to be procured in sufficient detail to permit full and open competition and allow bidders to properly respond to the invitation. Description and specifications shall conform to the requirements in Section 10.0243.

(f) Quantity of goods or services to be furnished.

(g) Time, place, and method of delivery or performance requirements.

(h) All requirements bidders must fulfill and other factors (if any) to be used in evaluation bids.

(i) Clauses required by Subsection 10. 0260 (d) of Section 10.0260.

(j) Bonding requirements for construction as required by subsection 10.0250 (b).

(k) Local preference evaluation factors when required by subsection 10.0272.

(l) Optional form (OF) 17, sealed bid label.

(3) Public notice. Public notice of the Request for Proposals shall be made at least one week prior to issuance date of the invitation. Such notice shall be furnished to all suppliers of the goods or services being procured who have requested to be included in bidders mailing lists; shall be published in a newspaper of general circulation in American Samoa, and foreign newspaper if required; and displayed at the office of the chief procurement officer, the U.S. Post Office, and at other appropriate public places. The notice shall contain:

(a) Request for Proposals number.

(b) Adequate description of the types and quantities of goods and services to be furnished.

(c) Information on how to obtain copies of the Request for Proposals, including any charges as required by subsection 10.0250(a).

(4) Bidding time. A reasonable time for prospective bidders to prepare and submit bids shall be allowed in all invitations, consistent with the needs of the government. A bidding time of 30 calendar days shall be provided, unless the chief procurement officer determines a shorter period is reasonable and necessary.

(5) Bidders mailing list. A list of potential bidders and suppliers requesting copies of invitations for bids in response to public notices shall be compiled and maintained by the chief procurement officer.

(6) Bid receipt. Bids, where received at the location specified in the Request for

Proposals, prior to the time set for opening, shall be kept unopened and secure in a locked receptacle. Bids which are opened by mistake shall be resealed in the envelope and the person who opened the bid shall write his signature and title on the envelope and deliver it to the chief procurement officer. No information contained in the bid shall be disclosed prior to bid opening.

(7) Bid opening. The bid opening official designated by the chief procurement officer shall determine when the time established for bid opening in the Request for Proposals has arrived and shall so declare to those present including at least one or more witnesses from government. All bids received prior to the time set for bid opening shall then be publicly opened, read aloud to the persons present, and recorded as to the name of the bidder and the amount of each bid.

(8) Recording of bids. The Request for Proposals number, bid opening date, names and addresses of bidders, prices bid, and evaluation as may be required by subsection 10.272 shall be entered in an abstract or record and shall be open to public inspection by interested persons. The record shall be completed as soon as practicable after the bid opening and the bid opening official shall certify the accuracy of the record.

(9) Bid Acceptance and evaluation. Bids shall be unconditionally accepted without alteration or correction except as authorized under paragraph (10) or (11). Bids shall be evaluated based on the requirements set forth in the Request for Proposals, which may include criteria as is necessary to reasonably permit a determination as to the acceptability of the bid. No criteria may be used in bid evaluation that are not set forth in the Request for Proposals.

(10) Bid rejection. A bid may be rejected for any of the following reasons, as determined in writing by the chief procurement officer:

(a) Failure to conform to essential requirements of the Request for Proposals such as specifications or time of delivery.

(b) Imposition of conditions or restrictions in the bid which modify requirements of the invitation or limit the bidders liability to the government. For example, bids shall be rejected in which the bidder:

(I) Protects against future changes in conditions. Such as increased costs;

(II) Fails to state a price and indicates that price shall be the price in effect at time of delivery;

(III) States a price but qualifies it as subject to price in effect at time of delivery;

(IV) Limits the rights of the government under any Request for Proposals provisions. A low bidder may be requested to delete objectionable limitations from a bid provided such conditions do not affect price, quantity, quality, or delivery of the goods or services offered.

(d) A low bid from a nonresponsible bidder as determined in accordance with section 10.0233.

(e) Failure to furnish a bid guarantee as required by subsection 10.0250(b).

(11) Correction or withdrawal of bids; cancellation of awards. Correction or withdrawal of inadvertently erroneous bids, before or after award, or cancellation of awards or contracts based on such bid mistakes must be supported by a written determination made by the chief procurement officer and approved by the Attorney General or designee. After bid opening, no changes in bid price or other provisions of bids prejudicial to the interest of the government or fair competition shall be permitted. A suspected bid mistake requires the government to request confirmation of the bid. Where there is an appearance of an obvious mistake, the bidder shall be requested to reconfirm the bid prior to award. In such an instance, if the bidder alleges an error the government shall only permit correction of the bid or withdrawal of the bid in accordance with subparagraph (A) or (B) below.

(a) Correction of bids. Correction of bid shall only be permitted when:

(1) An obvious clerical mistake is clearly evident from examining the bid document. Example of such mistakes are: obvious misplacement of a decimal point; errors in extension of unit prices; errors in addition; and obvious mistakes in designation of a unit or

(II) The otherwise low bidder alleges a mistake and the intended bid is evident from the bid document or is otherwise supported by clear and convincing evidence in the form of bid worksheets or other information which supports the bid intended and the bid, as corrected, remains the low bid. A low bid may not be permitted to correct a bid mistake resulting from an error in judgment.

(b) Withdrawal of bids. Withdrawal of a bid shall only be permitted where the otherwise low bidder alleges a mistake and there is clear and convincing evidence as to the existence of a mistake but not as to the bid intended.

(1) Evidence as to the existence of the mistake is not discovered until after award;

(II) There exists no clear and convincing evidence to support the bid intended; and

(III) Performance of the contract at the award price would be unconscionable.

(l2) Award. A contract shall be awarded with reasonable promptness by written notice to the lowest reasonable, responsive, responsible bidder whose bid fully meets the requirements of the Request for Proposals and the rules set forth in this chapter. Unsuccessful bidders shall be promptly notified.

(13) Negotiation after opening of bids. After the opening of bids, if all bids exceed available funds as certified under section 10.0221, and the bid of the lowest responsive and responsible bidder does not exceed those funds by more that 5%, and time and economic considerations preclude re-solicitation of the work at a reduced scope, the chief procurement officer is authorized to negotiate an adjustment of the bid price, including changes in Request for Proposals requirements, with the lowest responsive and responsible bidder in order to bring the bid price within the amount of the available funds. The negotiation of the price and changes in bid requirements shall be documented in written determination made by the chief procurement officer and included in the contract file.

(e) Negotiation.

(1) Competitive

(a) Conditions for use. Contracts may be awarded by competitive negotiation when the chief procurement officer determines in writing that the use of competitive sealed bidding under subsection 12.0231(d) is not practicable because of the nature of the goods or services to be procured.

(b) Requests for proposals. A request for proposals shall be issued and shall include:

(I) Request for proposal number.

(II) Date of Issuance

(III) Name, address, and location of issuing office including address for submission of proposals.

(IV) Date for submission of proposals.

(V) Description of the required goods or services to be procured.

(VI) Evaluation criteria to be used by the government in evaluating proposals on a technical and cost basis. The relative importance of the evaluation criteria shall be stated so all offerors clearly understands the basis of award.

(VII) Instructions for offerors to use in submitting technical and cost proposals, including number of copies required.

(VIII) Quantity of goods or services to be furnished.

(IX) Time, place, and method of delivery or performance requirements

(X) Clauses required by section 10.0260

(d) Proposal times. Proposal times shall conform to the requirements in paragraph 10.0231(d) (4).

(e) Offerors mailing list. A list of prospective offerors shall be prepared in accordance with the requirements of paragraph 10.0231(d) (5).

(f) Receipt of proposals. Proposals shall be opened and used only by government personnel authorized to participate in evaluation. No information contained in a proposal shall be disclosed to the public until after contract award. Proposals shall be protected so as to avoid disclosure of contents to competing offerors.

(g) Evaluation. Proposals shall be evaluated by the government in accordance with the evaluation criteria contained in the request for proposals. No other criteria may be used. The results of the evaluation shall be documented and a determination shall be made by the Chief procurement officer of those responsible offerors whose proposals are reasonably susceptible of being selected for award. The determination shall be included in the contract file.

(h) Discussions. Discussions shall be conducted with those responsible offerors whose proposals are determined by the chief procurement officer to have a reasonably susceptible chance of being selected for award. These discussions shall be conducted for the purpose of obtaining clarification from the offeror on its proposal to ensure full understanding of, and responsiveness to the request for proposal requirements. Discussions shall be conducted individually with each offeror and care shall be exercised to ensure that no information derived from competing offerors proposal is disclosed. All offerors with whom discussions are conducted shall be afforded the same time period to revise their proposals and submit a best and final offer to the government based on the discussions.

(i) Final offers. Best and final offers received from offerors shall be evaluated by the government using the evaluation criteria contained in the request for proposals and the results shall be documented and included in the contract file.

(j) Award. Award shall be made to the responsible offeror whose proposal is determined in writing by the chief procurement officer to be most advantageous to the government considering price and the evaluation criteria contained in the request for proposal. Unsuccessful offerors shall be promptly notified.

(2) Noncompetitive.

(a) Conditions for use. Contracts may be awarded without competition when the chief procurement officer determines in writing that award of a contract is infeasible under small purchase, competitive sealed bidding, or competitive negotiation procedures and that there is only one source available to furnish the required construction, goods, or services. The written determination shall be prepared by the requisition initiator and shall contain the following information:

(I) The unique capabilities of the source that are required why they are required, and the degree of consideration given to other sources.

(II) The facilities or equipment of the source that are required, why they are required and if they are unavailable from other sources.

(III) Whether the work is a continuation of contract work previously performed by the source and the additional time, expense, or duplication of effort required to bring another source up to that level.

(IV) Whether drawings or specification suitable for competitive negotiation are available. If unavailable, explain why and the time and expense required to develop them.

(V) Other sources given consideration and specific reasons why they lack the qualifications required for the procurement.

(f) Emergency Procurement.

(1) Conditions for use. Notwithstanding any other provision of this chapter, the governor may make or authorize a governmental body to make an emergency procurement where there exists a threat to public health, welfare, or safety under emergency conditions as defined under Section 26.0105(d) ASCA. An emergency procurement must be as competitive as practicable under the circumstances.

(2) Documentation. A written determination describing the basis for the emergency, the extent of competition obtained, and the basis for selection of a particular contractor shall be prepared, reviewed by the Attorney General, and approved by the Governor, before contract award. The determination shall be included in the contract file. History: Rule 5-84, eff 11 Jul 84, (part).

10.0232 Cancellation of solicitations. An invitation for bids or request for proposals may be cancelled, and any or all bids or proposals may be rejected, when such action is determined writing by the chief procurement officer to be in the best interest of the government based on:

(a) Inadequate or ambiguous specifications contained in the solicitation;

(b) Specifications which have been revised;

(d) Inadequate consideration given to all factors of cost to the government in the solicitation;

(e) Bids or proposals received indicate that the needs of the government can be satisfied by a less expensive good or service;

(f) All otherwise acceptable bids or proposals received are at unreasonable prices; or

(g) Bids were collusive (see subsection 10.0292(I)). History: Rule 5-84, eff 11 Jul 84, (part).

10.0233 Qualifications and duties

(a) Responsibility of bidders and offerors. Awards shall be made only to responsible contractors.

(1) Responsibility factors. To be determined responsible, a prospective contract must;

(a) Have adequate financial resources to perform the contract or the ability to obtain them;

(b) Be able to comply with the required delivery or performance schedule;

(d) Have a satisfactory record of integrity and business ethics;

(e) Have the necessary organization, experience, and skills (or ability to obtain them), required to successfully perform the contact;

(f) Have the necessary production, construction, and technical equipment and facilities (or the ability to obtain them); and

(g) Be otherwise qualified and eligible to receive an award under applicable laws and rules.

(2) Obtaining information. Prior to award, the government official delegated authority to execute and administer a contract shall obtain information from the bidder or offeror necessary to make a determination of responsibility using the factors in paragraph (1) above. The unreasonable failure of a bidder or offeror to promptly supply information in connection with an inquiry with request to responsibility may be grounds for a non-responsibility determination under paragraph (4) below. Information furnished by a bidder or offeror pursuant to this paragraph may not be disclosed outside of the office of the chief procurement officer or the purchasing agency without prior written consent by the bidder or offeror.

(3) Responsibility determination. The signing of a contract shall constitute a determination that the prospective contractor is responsible.

(4) Nonresponsibility determination. When a bid or proposal on which a contract award would otherwise be made is rejected because the prospective contractor is found to be non responsible, a written determination shall be signed by the government official delegated authority to execute the contract and shall state the basis for the determination. The determination shall be placed in the contract file.

(b) Pre-Qualification. Prospective suppliers of goods or services may be prequalified for a particular types of construction, goods, and services when determined necessary by the chief procurement officer. Opportunity for qualification before solicitation shall be afforded to all suppliers. Solicitation mailing lists of potential contractors shall include but shall not be limited to pre-qualified suppliers. History: Rule 5-84, eff 11 Jul 84, (part).

10.0234 Types of Contracts.

(a) Use of a cost-plus-a-percentage-of-cost and percentage of construction cost method of contacting are prohibited.

(b) Normally, a firm-fixed-priced contact shall be used unless use of a cost reimbursement contract is justified under subsection (c) below.

(1) Uncertainties in the work to be performed make the cost of performance too difficult to estimate with the degree of accuracy required for a firm-fixed-price contract.

(2) Use of a firm-fixed-price contract could seriously affect the contractor’s financial stability or result in payment by the government for contingencies that never occur; or

(3) Use of a cost reimbursement contract is likely to be less costly to the government than any other type due to the nature of the work to be performed under the contract.

(d) The chief procurement officer shall develop, issue, and maintain procedures for the preparation of contract documents. History: Rule 5-84, eff 11 Jul 84, (part).

V. SPECIFICATIONS

10.0240 Definitions. As used in this article, the following definition shall apply:

(a) “Specification” means any description of the physical or functional characteristics, or of the nature of a supply, service, or construction item. It may include a description of any requirement for inspecting, testing, or preparing a good, service, or constriction item for delivery. History: Rule 5-84, eff 11 Jul 84, (part).

10.0241 Duties of the Chief Procurement Officer.

(a) The chief procurement officer shall be responsible for monitoring the use of specifications for construction, goods, and services to be procured.

(b) The chief procurement officer may delegate this responsibility in writing to an official who has been delegated authority to execute and administer contracts. History: Rule 5-84, eff 11 Jul 84, (part).

10.0242 Maximum Practicable Competition. All specifications shall be written to promote overall economy for the purposes intended, encourage maximum competition in satisfying the government’s minimum needs, and shall not be unduly restrictive of competition. History: Rule 5-84, eff 11 Jul 84, (part).

10.0243 Use of specifications.

(a) Specifications shall not be written so as to specify a particular product, or a particular feature of a product, or a particular feature of a product peculiar to one manufacturer unless that particular product or feature is essential to the government’s requirements and products of other companies’ lacking the particular feature would not meet the minimum needs of the government.

(b) Specification shall, whenever practicable, include a description of the qualitative nature of the construction material, good, or service to be procured and, when necessary, set forth those minimum essential standards and characteristics to which it must conform to satisfy its intended use.

(c) When it is impracticable or uneconomical to make a clear and accurate description of the required good or service, a “brand name or equal” description may be used as provided in section 10.0224 as a means to define the performance or other salient characteristics of the requirement. History: Rule 5-84, eff 11 Jul 84, (part).

10.0244 Brand name or equal provision.

(a) “Brand name or equal” description shall be used only when it is determined that it is impracticable or uneconomical to make a clear, accurate, and detailed description of the government’s requirements without referring to a particular product.

(b) “Brand name or equal” description used in specifications shall set forth those salient physical, functional, or other characteristics of the referenced product which are determined to be essential to meet the minimum needs of the government. Such description shall include:

(1) Complete identification of the item required;

(2) Applicable model, make, or catalog number for each brand name referenced, and identity of the commercial catalog in which it appears;

(3) Name of manufacturer, producer, or distributor of each brand name product reference and address;

(4) Instructions for bidders or offerors to furnish for an “equal” product to be offered, the name of the product, manufacturer, model number, and all other information required for the government to determine that the offered product fully meets the salient characteristic requirements listed in the “brand name or equal” description. History: Rule 5-84, eff 11 Jul 84, (part).

10.0245 Specifications prepared by architects and engineers. The requirements of this article shall apply to all specifications prepared by architects and engineers for public contracts. History: Rule 5-84, eff 11 Jul 84, (part).

VI. PROCUREMENT OF CONSTRUCTION AND ARCHITECT-ENGINEER SERVICES

10.0250 Construction.

(a) Request for Proposals.

(1) Deposit. The chief procurement officer, or other official designated authority to execute and administer construction contracts, shall determine the amount of deposit required for potential bidders to obtain the Request for Proposals.

(2) Contents. The Request for Proposals shall be prepared in accordance with paragraph 10.0231 (d) (2). In addition, the following additional items shall be included in the form prescribed by the chief procurement officer.

(a) Notice to bidders. General information regarding project information.

(b) Instructions to bidders. Information on the preparation of bids, bid security requirements (subsection 10.0250 (b). and forms and certifications to be submitted with the bid.

(d) Special Conditions. Special contract clauses depending on the nature and dollar amount of the work to be performed.

(e) Technical specifications. Specifications governing the technical aspects of the work to be performed.

(f) Local bidder preference. Evaluation of local bidder preference as required under Section 10.0272.

(b) Bid Security.

(1) Requirement. Bid security shall be required for all competitive sealed bidding construction contracts where performance and contract bonds are required. Bid security shall be on bid bond (GSA Standard Form 24), in cash, by certified check, cashier’s check, or other form acceptable to government. The surety company shall hold a certificate of authority from the U.S. Secretary of the Treasure as an acceptable surety, or other surety acceptable to the government.

(2) Amount. Bid security shall be in an amount equal to at least 5% of the amount of the bid or other amount as specified in the Request for Proposals depending upon the source of funding.

(3) Rejection of bid. Failure to furnish bid security, when required by the invitation, shall result in rejection of the bid in accordance with subparagraph 10.0231 (d) (10 (E).

(1) Contract bond. A contract bond is required in cash, certified check, cashier’s check, or with sureties certified by the government on GAS Form PUB/WKS-49 or other similar form satisfactory to the government when the amount of the contract does not exceed $100,000.

(2) Performance and payment bonds. A performance bond and payment bond are required in cash, certified check, cashier’s check, or with sureties certified by the government on GSA form 25 and 25A or other similar form satisfactory to the government when the contract exceeds $100,000.

(3) Amount. The contract, performance, and payment bonds shall be in an amount sufficient to protect the government’s interest as determined by the chief procurement officer.

(4) Other bonds. Other bonds, such as labor and materials bonds, may be required in order to protect the interests of the government. Such bonds shall be required as determined by the chief procurement officer or other government official delegated authority to execute and administer construction contracts.

(d) Required contract provisions. The following clauses shall be included in all construction contracts as prescribed:

(1) For contracts exceeding $10,000, “Termination for convenience” (Appendix A).

(2) For contracts exceeding $10,000, “Termination for default” (Appendix B1).

(3) For contracts exceeding $10,000, Equal Opportunity” (Appendix C).

(4) “Anti-Kickback Statue” (Appendix D).

(5) When required by Federal grant program legislation and the contract exceeds $2,000, “Davis Bacon Act” (Appendix E).

(6) Where applicable for contracts in excess of $2,000, “Contract Work Hours and Safety Standards Act” (Appendix F).

(7) For contracts over $100,000, “Clean Air and Water” (Appendix G) unless this requirement has been waived by EPA

(8) Prohibition against gratuities and kickbacks as required by subsection 10.0292(f)

(9) Prohibition against contingent fees as required by subsection 10.0292(g).

(10) Prohibition against collusion as required by subsection 10.0292(i).

(e) Fiscal responsibility. Every contract modification, change order, or contract price adjustment under a construction contract shall be subject to prior written certification by the fiscal officer of the entity responsible for funding the project or the contract, or other official responsible for monitoring and reporting upon the status of the cost of the total project budget or contract budget, as to the effect of the contract modification, change order, or adjustment in contract price on the total project budget or the total contract budget. In the event that the certification of the fiscal officer or other responsible official discloses a resulting increase in the total project budget and/or the total contract budget, such contract modification, change order, or adjustment in contract price shall not be made unless sufficient funds are available therefore, or the scope of the project or contract is adjusted so as to permit the degree of completion that is feasible within the total project budget and/or total contract budget as it existed prior to the contract modification, change order, or adjustment in contract price under consideration; provided, however, that with respect to the validity, as to the contractor, of any executed contract modification, change order, or adjustment in contract price which the contractor has reasonably relied upon, it shall be presumed that there has been compliance with the provisions of this subsection. History: Rule 5-84, eff 11 Jul 84, (part).

10.0251 Architect – Engineer Services.

(a) Applicability. Architect-engineer services shall be procured as provided in this section except as authorize by subsection 10.0231 (d) (2) (noncompetitive negotiation) or subsection 10.0231(f) (emergency procurement).

(b) Policy. It is the policy to publicly announce all requirements for architect-engineer services and negotiate contracts on the basis of demonstrated competence and qualifications at a fair and reasonable price.

(c) Selection. The chief procurement officer or other official delegated authority to execute and administer architect-engineer contracts shall maintain files of current statements of qualifications of architect-engineer firms. After public announcement of a requirement for architect-engineer services, current statements shall be reviewed together with those that may be submitted by other firms in response to the announcement. Discussions shall be conducted with at least three of the firms regarding the contract requirements and technical approach and a selection made there from, in order of preference, of no less than three firms determined to be the most highly qualified to perform the services required.

(d) Negotiation. The chief procurement officer or other official delegated authority shall negotiate a contract with the highest qualified architect-engineer firm at a price determined to be fair and reasonable to the government. If a fair and reasonable price cannot be negotiated, negotiations shall be terminated and negotiations shall be undertaken with the second highest qualified firm. If a fair and reasonable price cannot be negotiated, negotiations shall be terminated and negotiations shall be undertaken with the third highest qualified firm. If a fair and reasonable price cannot be negotiated with any of the selected firms, the chief procurement officer or other official with delegated authority shall select additional firms in order of competence and qualifications and continue negotiations until a fair and reasonable price is agreed upon. History: Rule 5-84, eff 11 Jul 84, (part).

10.0252 Duties of the Chief Procurement Officer. The chief procurement officer may promulgate additional contract provisions as are required for construction or architect-engineer contracts. History: Rule 5-84, eff 11 Jul 84, (part).

VII. PROCUREMENT OF GOODS AND SERVICES.

10.0260 Required contract provision. The following clauses shall be included in all contracts as prescribed:

(a) For contracts in excess of $10,000, “Termination for Convenience” (Appendix A).

(b) For contracts in excess of $10,000, “Equal Opportunity” (Appendix C).

(c) For contracts in excess of $2,500 which involve employment of mechanics or laborers “Contract Work Hours and Safety Standards Act” (Appendix F).

(d) For contracts in excess of $2,500 which involve employment of mechanics or laborers “Contract Work Hours and Safety Standards Act” (Appendix F).

(e) For negotiated contracts, “Examination of Records” (Appendix I).

(f) For contracts over $100,000 “Clean Air and Water (Appendix G)

(g) For Contracts involving research, development, experimental or demonstration work, “Patents” (Appendix J)

(h) Prohibition against gratuities and kickbacks as required by subsection 10.0260(f)

(i) Prohibition against contingent fees as required by subsection 10.0260(g)

(j) Prohibition against collusion as required by subsection 10.0260(i).

10.0261 Duties of the chief procurement officer. The chief procurement officer may promulgate additional contract provisions as are required for contracts for goods and services. The chief procurement officer may require bid bonds and performance and payment bonds on contracts other than construction contracts upon a written determination that such additional security is necessary to protect the government’s interest.

VIII. SOCIOECONOMIC PROGRAMS

10.0270 Policy. It shall be the policy of the government to use its procurement rules to promote local business investment, activity, and competitiveness with other non-local business by decreasing cash outflow and assisting to overcome the limitation of size, isolation from the mainstream of commercial and financial activities, lack of diversified industrial bases, and inadequate availability of venture capital which have stymied business development. The government shall encourage economic activities and business development to the maximum extent feasible without compromising effective and efficient government procurement practices including competition.

10.0271 Definitions: As used in this article, the following definitions apply:

(a) “Local bidder” for procurement of goods and services means an individual, sole proprietorship, partnership, joint venture, corporation, other unincorporated association, or private legal entity which:

(1) Has a valid American Samoa business license and, if required, a foreign corporation permit to transact business in American Samoa, and

(2) Has its principal place of business in American Samoa; and

(3) Has owned, operated, or maintained an office, store, warehouse, or other facility in American Samoa for at least six months.

(4) Has, or has the ability to obtain, necessary technical support services, as may be required, for timely installation, maintenance, warranty, and repair of the goods to be furnished in the bid.

(b) “Local bidder” for procurement of construction means a sole proprietorship which is wholly owned by an American Samoan or a permanent resident as defined in 41.0502 ASCA, or a partnership, joint venture, or other unincorporated association which is wholly owned by those persons, or a corporation which is majority owned by those persons and has submitted a bid in response to an Request for Proposals for construction.

(c) “Off-Island bidder” means a person submitting a bid in response to a Request for Proposals who does not qualify as a “local bidder” as defined in (a) and (b) above.

10.0272 Local bidder preference and evaluation.

(a) Construction procurements.

(1) For construction procurements where the contract value is estimated by the government at $50,000 or less, the procurement shall be set aside and restricted to local bidders only. Bids received from off-island bidders will be rejected.

(2) For all construction procurements where the contract value is estimated by the government to exceed $50,000, bids from off-island bidders shall be evaluated after bid opening so as to give preference to responsive, responsible and reasonable, and reasonable local bidders by application of the following schedule of add-on percentages to the bid amount submitted by the lowest responsive, responsible, and reasonable offisland bidder:

Estimated value Add-on Percentage

$50,001 to $100,000 10%

$100,001 to $200,000 $10,000 plus 5% of the amount in excess of $100,000

More that $200,000 $15,000

(b) Procurement of goods and services.

(1) For all procurements of goods or services (other than construction) for which qualifying bids are received from both local bidders and off-island bidders,

the bids shall be evaluated after bid opening so as to give preference to responsive, responsible and reasonable local bidders by application of the following schedule of add-on percentages to the bid amount submitted by the lowest responsive, responsible and reasonable off-island bidder:

Estimated Value Add-on Percentage

Up to $10,000 25%

$10,001 to $50,000 $2,500 plus 12% of the amount in excess of $10,000

$50,000 to $100,000 $7,300 plus 10% of the amount in excess of $50,000

$100,001 to $200,000 $12,300 plus 5% of the amount in excess of $100,000

More than $200,000 $17,300

(c) If, after the addition of the applicable add-on percentage amount according to subsection (a) or (b) above, the bid submitted by the lowest responsive, responsible, and reasonable local bidder is equal to or less than the evaluated bid (amount of bid plus add-on percentage of the bid) of the lowest responsive, responsible, and reasonable off-island bidder, then the local bidder shall be awarded the contract.

(d) Procurement requirements may not be artificially divided or combined so as to circumvent the provisions of this section.

(e) The Governor may suspend or reduce a local preference set forth in this section if he finds that such action is desirable or necessary in the public interest as a result of financial or economic conditions affecting directly or indirectly the government generally, for a period or periods not exceeding 18 months in total. The preferences suspended or reduced must be fully restored after 18 months unless permanent modifications are proposed to the legislature. Suspension or reduction shall be adopted under the Administrative Procedure Act, 4.1001 ASCA et seq.

IX. CONTRACT ADMINISTRATION

10.0280 Responsibilities. The chief procurement officer and other officials’ delegated authority to award and administer government contracts shall be responsible for monitoring contract performance in accordance with the terms, condition and specifications of the contract.

10.0281 Contract file documentation. For each contract awarded, an official contract file shall be established and contain the following information:

(a) Purchase requisition.

(b) Public notice.

(d) Request for Proposals or request for proposals.

(e) Bid abstract or record.

(f) Determination of non-responsibility, when applicable.

(g) Evaluation results (negotiated procurement).

(h) Notice of award to unsuccessful bidders or offerors.

(i) Contract.

(j) Non-competitive determination (when applicable).

(k) Emergency procurement determination (when applicable).

(l) Cost – reimbursement contract determination (when applicable).

(m) Basis for cost or price. History: Rule 5-84, eff 11 Jul 84, (part).

10.0282 Disputes and appeals.

(a) Definition “Disputes” means any disagreement between contractors or potential contractors and the government regarding a procurement officer’s decision on mistakes-in-bidding, source selection, contract interpretation, or termination for convenience or default.

(b) Requirements. All such disputes shall be submitted in writing to the procurement officer making the decision. The procurement officer shall acknowledge receipt of the dispute within 5 working days of receipt and shall render a final decision within 30 working days after receipt of the dispute.

(c) Appeals. Appeals of a procurement officer’s final decision in a dispute may be made within 60 days of the date of the decision provided such appeal is submitted in writing to the Governor. The Governor shall appoint a board of at least three persons knowledgeable of procurement to review such appeals and recommend appropriate action to the Governor. None of the board members shall have participated in the action under appeal. At least one of the board members shall be a qualified attorney. Hearing procedures and documentation shall be as set forth in the Administrative Procedure Act, Section 4.1025 ASCA et. seq., and the rules.

(d) Limitation. A termination for default may only be converted to a termination for convenience as a result of a finding by the appeals on behalf of the appellant. History: Rule 5-84, eff 11 Jul 84, (part).

X. ETHICAL CONDUCT STANDARDS FOR GOVERNMENT EMPLOYEES AND CONTRACTORS

10.0290 Policy. Public employment is a public trust. In governmental contracting, public employees shall discharge their duties impartially so as to assure fair competitive access to governmental procurement by responsible contractors and conduct themselves in a manner as to foster public confidence in the integrity of the government. History: Rule 5-84, eff 11 Jul 84, (part).

10.0291 Definitions. As used in this article, the following definitions shall apply:

(a) “Confidential Information” means any information which is available to an employee only because of the employee’s status as an employee of this government and is not a matter of public knowledge or available to the public on request.

(b) “Conspicuously” means written in such special or distinctive format, print, or manner that a reasonable person against whom it is to operate ought to have noticed it.

(c) “Direct or indirect participation” means involvement through decision, approval, disapproval, disapproval, recommendation, preparation of any part of a purchase request, influencing the content of any specification or procurement standard, rendering of advice, investigation, auditing, or in any other advisory capacity.

(d) “Financial interest” means:

(1) ownership of any interest or involvement in any relationship from which, or as a result of which, a person within the past year has received, or is presently or in the future entitled to receive compensation; or

(2) holding a position in a business such as an officer, director, trustee, partner, employee, or the like, or holding any position of management.

(e) “Gratuity” means a payment, loan, subscription, advance, deposit of money, services, or anything of more than nominal value, present or promised, unless consideration of substantially equal or greater value is received.

(f) “Immediate family” means a spouse, children, parents, brothers and sisters. History: Rule 5-84, eff 11 Jul 84, (part).

10.0292 Standards of ethical conduct.

(a) Ethical standards for employees. Any attempt to realize personal gain through public employment by conduct inconsistent with the proper discharge of the employee’s duties is a breach of a public trust. In order to fulfill this ethical standard, employees must meet the requirements of this section.

(b) Ethical standards for contractors. Any effort to influence any public employee to breech the standards of ethical conduct set forth in this section is also a breach of ethical standards.

(1) Disclosure of benefit received from contract. Any employee who has, or obtains any benefit from any government contract with a business in which the employee has a financial interest shall report such benefit to the chief procurement officer or designee.

(2) Failure to disclose benefit received. Any employee who knows or should have known of such benefit and fails to report such benefit is in breach of ethical standards of this section.

(d) Employee conflict of interest.

(1) Policy. It shall be a breach of ethical standards for any employee to participate directly or indirectly in a procurement when the employee knows that:

(a) the employee or any member of the employee’s immediate family has a financial interest pertaining to the procurement.

(b) A business or organization in which the employee, or any member of the employee’s immediate family, has a financial interest pertaining to the procurement: or

(c) any other person, business, or organization with whom the employee or any member of the employee’s immediate family is negotiating or has an arrangement concerning prospective employment is involved in the procurement.

(2) Discovery of actual or potential conflict of interest, disqualification, and waiver. Upon discovery of an actual or potential conflict of interest, an employee shall promptly file a written statement of disqualification and shall withdraw from further participation in the transaction involved.

(e) Use of confidential information. It shall be a breach of ethical standards for any employee or former employee knowingly to use confidential information for actual or anticipated personal gain, or for the actual or anticipated gain of any other person.

(f) Prohibition against gratuities and kickbacks.

(1) Gratuities. It shall be a breach of ethical standards for any person to offer, give, or agree to give any employee or former employee or for any employee or former employee to solicit, demand, accept, or agree to accept from another person, a gratuity or an offer of employment in connection with any decision, approval, disapproval, recommendation,

preparation of any part of a program requirement or a purchase request, influencing the content of any specification or procurement standard, rendering of advice, investigation, auditing, or in any other advisory capacity in any proceeding or application, request for ruling, determination, claim or controversy, or other particular matter, pertaining to any program requirement or a contract or subcontract, or to any solicitation or proposal therefore.

(2) Kickbacks. It shall be a breach of ethical standards for any payment, gratuity, or offer of employment to be made by or on behalf of a subcontractor under a contract to the prime contractor or higher tier subcontractor or any person associated therewith, as an inducement for the award of a subcontract or order.

(3) Contract clause. The prohibition against gratuities and kickbacks prescribed in this subsection shall be conspicuously set forth in every contracts and solicitation therefor.

(j) Prohibition against contingent fees.

(1) Contingent fees. It shall be a breach of ethical standards for a person to retained, or to retain a person, to solicit or secure a government contract upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee, except for retention of bona fide employees or bona fide established commercial selling agencies for the purpose of securing business.

(2) Representation of contractor. Every person, before being awarded a government contract, shall represent, in writing, that such person has not retained anyone in violation of this subsection. Failure to do so constitutes a breach of ethical standards.

(3) Contract clause. The representation prescribed in this subsection shall be conspicuously set forth in every contract and solicitation therefor.

(j) Prohibition Against Employee Use and Contractor Acceptance of Purchase Requisitions.

(1) Policy. Only valid purchase orders and contract awarded pursuant to this

chapter constitute legal and binding documents between the government and its contractors. The government shall not make payment to a contractor who delivered goods or services a result of receipt and acceptance of a purchase requisition, unless such purchase was authorized by this chapter.

(2) Notice. All purchase requisitions used by the government shall contain a

prominent notice on the face of the requisition form which sets forth the prohibition in this subsection.

(3) Employee Liability. Unless otherwise authorized by this chapter, any employee

who uses or attempts to use a purchase requisition to obtain goods or services directly from a contractor without first obtaining a valid purchase order or contract may be held personally liable and responsible for the amount of the goods and services.

(4) Ratification. Employee purchase for the government without the use of a valid

purchase order or contract are improper and illegal. Such actions may be ratified in exceptional circumstances by the chief procurement officer when such action is determined to be in the interest of the government. History: Rule 5-84, eff 11 Jul 84, (part).

10.0293 Civil Penalties.

(a) An employee who violates a provision of this chapter or the rules is subject to adverse action, including but not limited to reprimand, suspension without pay, or termination of employment, in addition to other penalties prescribed by law.

(b) A person other than an employee who violates a provision of this chapter or the rules shall be subject, by the procurement officer with which that person is dealing directly at the time of violation, to written warning of reprimand, termination of contract or transaction, or suspension from being a contractor or subcontractor under a government contract in addition to other penalties prescribed by law.

(c) All proceedings under this section must be in accordance with due process requirements, including but not limited to reasonable notice and opportunity for hearing, and must be conducted in accordance with the hearing procedures

prescribed by the Administrative Procedures Act, 4.1025 ASCA et seq., and the rules. History: Rule 5-84, eff 11 Jul 84, (part).

10.0294 Criminal penalties.

(a) Except as otherwise provided in this section, a violation of a provision of this chapter is punishable as a class B misdemeanor.

(b) A person who gives or receives anything of value for the purpose of securing of influencing the award of a contract subject to the provisions of this chapter, is upon conviction, guilty of a class C felony.

APPENDIX A

TERMINATION FOR CONVENIENCE

(a) The government may terminate performance of work under this contract in whole or, from time to time, in part if the contracting officer determines that a termination is in the government’s interest. The contracting officer shall terminate by delivering to the contractor a notice of termination specifying the extent of termination and the effective

date.

(b) After receipt of a notice of termination, and except as directed by the contracting officer, the contractor shall immediately proceed with the following obligations, regardless of any delay in determining or adjusting any amounts due under this clause:

(1). Stop work as specified in the notice.

(2). Place no further subcontracts or orders (referred to as subcontracts in this clause) for material, services or facilities, except as necessary to complete the continued portion of the contract.

(3). Terminate all subcontracts to the extent they relate to the work terminated.

(4). Assign to the Government, as directed by the contracting officer, all right, title.

And interest of the contractor under the subcontracts terminated, in which case the government shall have the right to settle or to pay any termination settlement proposal arising out of those terminations.

(5). With approval or ratification to the extent required by the contracting officer, settle all outstanding liabilities and termination settlement proposals arising from the termination of subcontracts: the approval or ratification will be final for purposes of this clause:

(6). As directed by the contracting officer, transfer title and deliver to the govern (please complete) (i) the fabricated or unfabricated parts, work in process. Completed work, supplies, and other material produced or acquired for the work terminated, and (ii) the completed or partially completed plans, drawings, information, and other property that, if the contract had been completed, would be required to be furnished to the government:

(7). Complete performance of the work not terminated.

(8). Take any action that may be necessary, or that the contracting officer may direct, for the protection and preservation of the property related to this contract that is in the possession of the contractor and in which the Government has or may acquire an interest.

(9). Use its best efforts to sell, as directed or authorized by the contracting officer, any property of the types referred to in subparagraph (6) of this subsection: provided, however, that the contractor (i) is not required to extend credit to any purchaser and (ii) may acquire the property under the conditions prescribed by, and at prices approved by, the contracting officer. The proceeds of any transfer or disposition will be applied to reduce any payments to be made by the government under this contract, credited to he price or cost of the work, or paid in any other manner directed by the contracting officer.

(c) The contractor shall submit to the contracting officer a list, certified as to quantity and quality, of termination inventory not previously disposed of excluding items authorized for disposition by the contracting officer. The contractor may request the government to remove those items or enter into an agreement for their storage. Within 15 days, the government will accept title to those items and remove them or enter into a storage agreement. The contracting officer may verify the list upon removal of the items, or if stored, within 45 days from submission of the list, and shall correct this list, as necessary, before settlement.

(d) After termination, the contractor shall submit a final termination settlement proposal to the contracting officer in the form and with the certification prescribed by the contracting officer. The contractor shall submit the proposal promptly, but no later than 1 year from the effective date of termination, unless extended in writing by the contracting officer upon written request of the contractor within this 1-year period. However, if the contracting officer determines that the facts justify it, a termination settlement proposal may be received and acted on after 1 year or any extension. If the contractor fails to submit the proposal within the time allowed, the contracting officer may determine, on the basis of information available, the amount, if any due the contractor because of the termination and shall pay the amount determined.

(e) Subject to paragraph (d) of this appendix, the contractor and the contracting officer may agree upon the whole or any part of the amount to be paid because of the termination. The amount may include a reasonable allowance for profit on work done. However, the agreed amount, whether under this paragraph (e) may not exceed the total contract price as reduced by (1) the amount of payments previously made and (2) the contract price of work not terminated. History: Rule 5-84, eff 11 Jul 84, (part).

APPENDIX B1

TERMINATION FOR DEFAULT (CONSTRUCTION)

If the contractor refuses or fails to prosecute the work, or any separable part thereof, with such diligence as will insure its completion within the time specified in the contract, or any extension thereof, or fails to complete said work within such time, the government may, by written notice to the contractor, terminate his right to proceed with the work or such part of the work as to which there has been delay. In such event the government may take over the work and prosecute the same to completion, by contract or otherwise, and may take possession of and utilized in completing the work such materials, appliances, and plant as may be on the site of the work and necessary therefore. Whether or not the contractor’s right to proceed with the work is terminated, he and his sureties shall be liable for any damage to the government resulting from his refusal or failure to complete the work within the specified time. If the government so terminates the contractor’s right to proceed, the resulting damage will consist of the fixed and agreed liquidated damages if stipulated elsewhere in this contract until such reasonable time as may be required for final completion of the work together with any increased costs occasioned the government in completing the work. If the government does not so terminate the contractor’s right to proceed, the resulting damage will consist of the fixed and agreed liquidated damages if stipulated elsewhere in this contract until the work is complete or accepted. The contractor’s right to proceed shall not be so terminated nor the contractor charged with resulting damage if:

(1). The delay in the completion of the work arises from causes other than normal weather beyond the control and without the fault or negligence of the Contractor, including but not restricted to, acts of God acts of the public enemy, acts of the government in either its sovereign or contractual capacity, acts of another contractor to the government in the performance of a contract with the government, fires floods, epidemics, quarantine restrictions, strikes, freight embargoes, unusually severe weather for American Samoa taking into consideration that approximately 200 inches of rainfall annually is normal, or delays of subcontractors or suppliers arising from causes other than normal weather beyond the control and without the fault or negligence of both the Contractor and such subcontractors or suppliers:

(2). The Contractor, within 10 days from the beginning of any such delay notifies the Contracting Officer in writing of the cause of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his judgment, the findings of fact justify such an extension, and his findings of facts shall be final and conclusive on the parties, subject only to appeal. If, after notice of termination of the contractor’s right to proceed under the provision of this section, it is determined for any reason that the contractor was not in default under the provisions of the section, the rights and obligations of the parties shall be the same as if a notice of termination for convenience had been issued. The rights and remedies of the government provided in this section are in addition to any other rights and remedies provided by law or under this contract. History: Rule 5-84, eff 11 Jul 84, (part).

APPENDIX B2

TERMINATION FOR DEFAULT (GOODS & SERVICES)

(1) Default. If the contractor refuses or fails to perform any of the provisions of this contract with such diligence as will ensure its completion within the time specified in this contract, or any extension thereof, otherwise fails to timely satisfy the contract provisions, or commits any other substantial breach of this contract, the procurement officer may notify the contractor in writing of the delay or nonperformance; and if not cured in ten days or any longer time specified in writing by the procurement officer, such officer may terminate the contractor’s right to proceed with the contract or such part of the contract as to which there has been delay or a failure to properly perform. In the event of termination in whole or in part the procurement officer may procure similar supplies or services in a manner and upon terms deemed appropriate by the procurement officer. The contractor shall continue performance of the contract to the extent it is not terminated and shall be liable for excess costs incurred in procuring similar goods or services.

(2) Contractor’s Duties. Notwithstanding termination of the contract and subject to any directions from the procurement officer, the contractor shall take timely reasonable, and necessary action to protect and preserve property in the possession of the contractor in which the government has an interest.

(3) Compensation. Payment for completed supplies delivered and accepted shall be at the contract price. Payment for the protection and preservation of property shall be at the contract price. Payment for the protection and preservation of property shall be in an amount agreed upon by the contractor and procurement officer. The government may withhold from amounts due the contractor such sums as the procurement officer deems to be necessary to protect the government against loss because of outstanding liens or claims of former lien holders and to reimburse the government for the excess costs incurred in procuring similar goods and services

(4) Excuse for Nonperformance or delayed Performance. Except with respect to defaults of subcontractors, the contractor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by the contractor to make progress in the prosecution of the work hereunder which endangers such performance) if the contractor has notified the procurement officer within 15 days after the cause of the delay and the failure arises out of causes such as, acts of God, acts of the public enemy, acts of the government and any other governmental entity in its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes or other labor disputes, freight embargoes, or unusual severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, the contractor shall not be deemed to be in default, unless the supplies of services to be furnished by the subcontractor were reasonable obtainable from other sources in sufficient time to permit the contractor to meet the contract requirements. Upon request of the contractor, the procurement officer shall ascertain the facts and extent of such failure, and, if such officer determines that any failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, the contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the government under the clause entitled “Termination for Convenience.”

(5) Erroneous Termination for Default. If, after notice of termination of the contractor’s right to proceed under the provisions of this clause, it is determined for any reason that the contractor was not in default under the provisions of this clause, the right and obligations of the parties shall, if the contract contains a clause providing for termination for convenience, be the same as if the notice of termination had been issued pursuant to such clause.

(6) Additional Rights and Remedies. The rights and remedies provided in this clause are in addition to any other rights and remedies provided by law or under this contract. History: Rule 5-84, eff 11 Jul 84, (part).

- 41 -

APPENDIX C

EQUAL OPPORTUNITY

(The following clause is applicable unless this contract is exempt under the rules, regulations, and relevant orders of the Secretary of Labor ( 41 CFR, ch. 60 ))

During the performance of this contract, the contractor agrees as follows:

(a) The contractor will not discriminate against any employee or applicant for employment because of race, color, religion, sex, or national origin. The contractor will take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, sex, or national origin. Such action shall include, but not be limited to the following: employment upgrading demotion or transfer: recruitment or recruitment advertising: layoff or termination; rates of pay or other forms of compensation: and selection for training, including apprenticeship. The contractor agrees to post in conspicuous places available to employees and applicants for employment, notices to be provided by the contracting officer setting forth the provisions of this equal opportunity clause.

(b) The contractor will, in all solicitations or advertisements for employees placed by or on behalf of the contractor, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, sex, or national origin.

(c) The contractor will send to each labor union or representative of workers with which he has a collective bargaining agreement or other contract or understanding, a notice, to be provided b the agency contracting officer, advising the labor union or worker’s representative of the contractor’s commitments under this equal opportunity clause, and shall post copies of the notice in conspicuous places available to employees and applicants for employment.

(d) The contractor will comply with all provisions of Executive Order No. 11375 of October 13, 1967, and of the rules, regulations, and relevant orders of the Secretary of Labor.

(e) The contractor will furnish all information and reports required by Executive Order No. 11246 of September 24, 1965, as amended by Executive Order No. 11375 of October 13, 1967, and by the rules, regulations, and orders of the secretary of Labor, or pursuant thereto, and will permit access to his books, records, and account by the contracting agency and the Secretary of Labor for purpose of investigation to ascertain compliance with such rules, regulations, and orders.

(f) In the event of the contractor’s noncompliance with the Equal Opportunity clause of this contract or with any of the said rules, regulations, orders, this contract may be cancelled, terminated, or suspended, in whole or in part, and the contractor may be declared ineligible for further government contracts in accordance with procedures authorized in Executive Order No. 11246 of September 24, 1965, as amended by Executive Order 11373 of October 13, 1967; and such other sanctions may be imposed and remedies invoked as provided in Executive Order No.11246 of September 24, 1965, as amended by Executive Order No. 11375 of October 13, 1967, or by rule, regulation, or order of the Secretary of Labor, or as otherwise provided by law.

(g) The contractor will include the provisions of paragraphs ( a) through ( g) in every subcontract or purchase order unless exempted by rules, regulations, or orders of the Secretary of Labor issued pursuant of section 204 of Executive Order No. 11246 of September 24, 1965, as amended by Executive Order No. 1965, as amended by Executive Order No. 11375 of October 13, 1967, so that such provisions will be binding upon each subcontractor or vendor. The contractor will take such action with respect to any subcontract or purchase order as the government may direct as a means of enforcing such provisions, including sanctions for noncompliance; including sanctions for noncompliance; provided, however, that in the event the contractor becomes involved in, or is threatened with, litigation with a subcontractor or vendor as a result of such direction by the contracting agency, the contractor may request the government to enter into such litigation to protect the interests of the government. History: Rule 5-84, eff 11 Jul 84, (part).

APPENDIX D

“ANTI-KICKBACK STATUTE”

The contractor shall comply with the Copeland “Anti-Kick Back” Act (18-USC 874) as supplemented in Department of Labor Regulations (29 CFR Part 3). TITLE 18, U.S.C., Section 874: “874. Kick-Back from public works employees; Whoever by force, intimidation, or threat of procuring dismissal from employment, or by any other manner whatsoever induces any person employed in the construction, prosecution, completion or repair of any public building, public work, or building or work financed in whole or in part by loans or grants form the United States, to give up any part of the compensation to which he is entitled under his contract of employment, shall be fined not more than $5,000.00 or imprisoned not more than five years, or both." - History: Rule 5-84, eff 11 Jul 84, (part).

APPENDIX E

DAVIS-BACON ACT

The following clause must be included in all construction contracts which are subject to the Davis-Bacon Act provisions:

(1) Minimum wages. (i) All mechanics and laborers employed or working upon the site of the work, or under the United States Housing act of 1937 or under the Housing Act of 1949 in the construction or development of the project, will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account (except such payroll deductions as are permitted by regulations issued by the Secretary of Labor under the Copeland Act (29CFR Part 3)), the full amounts due at time of payment computed at wage rates not less than those contained in the wage determination decision of the Secretary of Labor which is attached hereto and made a part hereof, regardless of any contractual relationship which may alleged to exist between the contractor and such laborers and mechanics and the wage determination decision shall be posted by the contractor at the site of the work in a prominent place where it can be easily seen by the workers. For the purpose of this clause, contribution made or costs reasonably anticipated under section 1(b) (2) of the Davis-Bacon Act on behalf of laborers or mechanic are considered wages paid to such laborers or mechanics, subject to the provisions of 29 CFR 5.5(a) (1) (iv). Also for the purpose of this clause, regular contributions made or costs incurred for more than a weekly period under plans, funds, or programs, but, covering the particular weekly period, are deemed to be constructively made or incurred during such weekly period.

(ii) The contracting officer shall require that any class of laborers or mechanics, including apprentices and trainees, which is not listed in the wage determination and which is to employed under the contract, shall be classified or reclassified conformably to the wage determination and a report of the action taken shall be sent by the federal agency to the Secretary of Labor. In the event the interested parties cannot agree on the proper classification or reclassification of a particular class of laborers and mechanics, including apprentices and trainees, to be used, the question accompanied by the recommendation of the contracting officer shall be referred to the Secretary for final determination.

(iii) The contracting officer shall require, whenever the minimum wage rate prescribed in the contract for a class of laborers or mechanics includes a fringe benefit which is not expressed as an hourly wage rate and the contractor is obligated to pay a cash equivalent of such a fringe benefit, an hourly cash equivalent thereof to be established. In the event the interested parties cannot agree upon a cash equivalent of the fringe benefit, the question, accompanied by the recommendation of the contracting officer, shall be referred to the Secretary of Labor for determination.

(iv) If the contractor does not make payment s to a trustee or other third person, he may consider as part of the wages of any laborer or mechanic the amount of any costs reasonably anticipated in providing benefits under a plan or program of a type expressly listed in the wage determination decision of the Secretary of Labor which is a part of this contract: Provided, however, the Secretary of Labor has found, upon the written request of the contractor, that the applicable standards of the Davis-Bacon Act have been met. The Secretary of Labor may require the contractor to set aside in a separate account assets for the meeting of obligations under the plan or program.

(2) Withholding. The government may with-hold or cause to b e withheld from the contractor so much of the accrued payments or advances as may be considered necessary to pay laborers and mechanics, including apprentices and trainees, employed by the contractor or any subcontractor on the work the fully amount of working on the site of the work or under the United States Housing Act of 1937 or under the Housing Act of 1949 in the construction or development of the project, all or part of the wages required by the contract, the government may, after written notice to the contractor, sponsor, applicant, or owner, take such action as may be necessary to cause the suspension of any further payment, advance or guarantee of funds until such violations have ceased.

(3) Payrolls and Basic Records.

(i) Payrolls and basic records relating thereto will be maintained during the course of the work and preserved for a period of three years thereafter for all la laborers and mechanics working at the site of the work, or under the United States Housing Act of 1937, or under the Housing Act of 1949, in the construction or development of the project. Such records will contain the name and address of each such employee, his correct classification, rates of pay (including rates of contributions or costs anticipated of the types described in section 1 (b) (2) of the Davis-Bacon Act), daily and weekly number of hours worked, deductions made and actual wages paid. Whenever the Secretary of Labor has found under 29 CFR 5.5(a) (1) (iv) that the wages of any laborer or mechanic include the amount of any costs reasonably anticipated in providing benefits under a plan or program described in section 1 (b) (2) (B) of the Davis-Bacon Act, the contractor shall maintain records which show that the commitment to provide such benefits is enforceable, that the plan or program is financially responsible, and that the plan or program has been communicated in writing to the laborers or mechanics affected, and records which show the costs anticipated or the actual cost incurred in providing such benefits.

(ii) The contractor will submit weekly a copy of all payrolls to the contracting officer if the agency is a party to the contract, but if the agency is not such a party the contractor will submit the payrolls to the applicant, sponsor, or owner, as the case may be for transmission to the government. The copy shall be accompanied by a statement signed by the employer or his agent indicating that the payrolls are correct and complete, that the wage rates contained therein are not less than those determined by the Secretary of Labor under (29 CFR, Part 3 ) and the filing with the initial payroll or any subsequent payroll of a copy of any findings by the Secretary of labor under 29 CFR 5.5(a) (1) (iv) shall satisfy this requirement. The prime contractor shall be responsible for the submission of copies of payrolls of all subcontractors. The contractor will make the records required under the labor standards clauses of the contract available for inspection by authorized representatives to interview employees during working hours on the job. Contractors employing apprentices or trainees under approved programs shall include a notation on the first weekly certified payrolls submitted to the contracting agencies that their employment is pursuant to an approved program and shall identify the program.

(4) Apprentices and Trainees.

(i) Apprentices. Apprentices will be permitted to work at less than the predetermined rate for the work they performed when they are employed and individually registered in a bona fide apprenticeship program registered with the U.S. Depart of Labor, Employment and Training Administration, bureau of Apprenticeship and Training, or with a state apprenticeship agency recognized by the bureau, or if a person is employed in his first 90 days of probationary employment as an apprentice in such an apprenticeship program, who is not individually registered in the program, but who has been certified by the Bureau of apprenticeship and Training to be eligible for probationary employment as an apprentice. The allowable ratio of apprentices to journeymen in any craft classification shall not to be paid the wage rate determined by the Secretary of Labor for the classification of work he actually performed. The contractor or subcontractor will be required to furnish to the contracting officer or a representative of the Wage-Hour Division of the U.s. Department of Labor written evidence of the registration of his program and apprentices as well as the appropriate ratios and wage rates (expressed in percentages of the journeyman hourly rates), for the area of construction prior to using any apprentices on the contract work. The wage rate paid apprentices shall be not less than the appropriate percentage of journeyman’s rate contained in the applicable wage determination.

(ii) Trainees. Except as provided in 29 CFR 5.15 trainees will not be permitted to work at less than the predetermined rate for the work performed unless they are employed pursuant to and individually registered in a program which has received prior approval, evidenced by formal certification by the U.S, Department of Labor Employment and Training Administration, Bureau of Apprenticeship and Training. The ratio of trainees to journeymen shall not be greater than permitted under the plan approved by the Bureau of Apprenticeship and Training Every trainee must be paid at not less than the rate specified in the approved program from his level of progress. Any employee listed on the payroll at a trainee rate who is not registered and participating in a training plan approved by the Bureau of Apprenticeship and Training shall be paid not less than the wage rate determined by the Secretary of Labor for the classification of work he actually performed. The contract or subcontractor will be required to furnish the contracting officer or a representative of the Wage-Hour Division of the U.S. Department of Labor written evidence of the certification of his program, the registration of the trainees, and the ratios and wage rates prescribed in that program. In the event the Bureau of Apprenticeship and Training withdraws approval of a training program, the contractor will no longer be permitted to utilized trainees at less than the applicable predetermined rate for the work performed until an acceptable program is approved.

(iii) Equal Employment Opportunity. The utilization of apprentices, trainees and journeymen under this part shall be in conformity with the equal employment opportunity requirements of Executive Order 11246, as amended, and 29 CFR Part 30.

(5) Compliance with Copeland Regulations (29 CFR Part 3). The contractor shall comply with the Copeland Regulations (20 CFR Part 3) of the Secretary of Labor which are herein incorporated by reference.

(6) Subcontracts. The contractor will insert in any subcontracts the clauses contained in 29 CFR 4.4(a) (1) through (5) and (7) and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts which they may enter into, together with a clause requiring this insertion in any further subcontracts that may in turn be made.

(7) Contract termination. A breach of clauses (1) through (6) may be grounds for

termination of the contract. Additional provisions which must be included are:

(1) Overtime requirements. No contractor or subcontractor contracting for any part of the contract work which may require or involve the employment of laborers or mechanics shall require or permit any laborer or mechanic in any workweek in which he is employed on such work to work in excess of eight hours in any calendar day or in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times his basic rate of pay for all hours worked in excess of eight hours in any calendar day or in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times his basic rate of pay for all hours worked in excess of eight hours in any calendar day or in excess of forty hours in such workweek, as the case may be.

(2) Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in subparagraph (1), the contractor and any subcontractor responsible therefore shall be liable o any affected employee for his unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contractor for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic employed in violation of the clause set forth in subparagraph (1), in the sum of $10 for each calendar day on which such employee was required or permitted to work in excess of eight hours or in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in subparagraph (1).

(3) Withholding for unpaid wages and liquidated damages. The government may withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor, such sums as may administratively be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in subparagraph (2).

(4) Subcontracts. The contractor shall insert in any subcontracts the clauses set forth in subparagraphs (1), (2), and (3) of this paragraph and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts which they may enter into, together with a clause requiring this insertion in any further subcontracts that may in turn be made. History: Rule 5-84, eff 11 Jul 84, (part).

APPENDIX F

CONTRACT WORK HOURS AND SAFETY STANDARDS ACT OVERTIME COMPENSATION

This contract, to the extent that it is of a character specified in the Contract Work hours and Safety Standards Act (40 USC 327-33), is subject to the following provisions and to all other applicable provisions and exceptions of such Act and the regulations of the Secretary of Labor there under.

(a) Overtime Requirements. No contractor or subcontractor contracting for nay part of the contract work which may require or involve the employment of laborers mechanic apprentice, trainee, watchman, or guard in any work week in which he is employed on such work to work subject to the provisions of the Contract Work Hours and Safety Standards Act unless such laborer, mechanic, apprentice, trainee, watchman or guard receives compensation at a rate not less than one and one-half times his basic rate of pay for all such hours worked in excess of 8 hours in any calendar day or in excess of 40 hours in such work week, whichever is the greater number of overtime hours.

(b) Violation; Liability for Unpaid Wages; Liquidated Damages. In the event of any violation of the provisions of paragraph (a), the Contractor and any subcontractor responsible therefore shall be liable to any affected employee for his unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer, mechanic, apprentice, trainee, watchman, or guard employed in violation of the provisions of paragraph (a) in the sum of $10 for each calendar day on which such employee was required or permitted to be employed on such work in excess of eight hours or in excess of his standard work week of 40 hours without payment of the overtime wage required by paragraph (a).

(c) Withholding for Unpaid Wages and Liquidated Damages. The contracting officer may withhold from the Government Prime Contractor, from any moneys payable on account of work performed by the contractor or subcontractor, such sums as may administratively be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the provisions of paragraph (b).

(d) Subcontracts. The contractor shall insert paragraph (a) through (d) of this clause in all subcontracts, and shall require their inclusion in all subcontracts of any tier. (e) Records. The contractor shall maintain payroll records containing the information specified in 20 CFR 516.2(a). Such records shall be preserved for three years from the completion of the contract.

APPENDIX G

CLEAN AIR AND WATER

(a) “Air Act, “ as used in this clause, means the Clean Air Act (42 USC 7401 et seq.). "Clean air standards," as used in this clause, means --

(1) Any enforceable rules, regulations, guidelines, standards, limitations, order, controls, prohibitions, work practices, or other requirements contained in, issued under, or otherwise adopted under the Air Act or Executive Order 11738;

(2) An applicable implementation plan as described in section 110(d) of the Air Act (42USC 7410(d)):

(3) An approved implementation procedure or plan under section 111(c0 or (d)):or section 111(d) of the Air Act (42 USC 7411(c) or (d));or

(4) An approved implementation procedure under section 112(d0 of the Air Act (42USC 7412 (d)). “Clean water standards.” As used in this clause means any enforceable limitation, control condition, prohibition, standard, or other requirement promulgated under the Water Act or contained in a permit issued to a discharger by the Environmental Protection Agency or by a State under an approved program, as authorized by section 402 of the Water Act (33 USC1342), or by local government to ensure compliance with pretreatment regulations as required by section 307 of the Water Act (33 U.S. C. 1317). "Compliance,” as used in this clause, means compliance with—

(1) Clean air or water standards; or

(2) A schedule or plan ordered or approved a court of competent jurisdiction, the Environmental Protection Agency, or an air or water control agency under the requirements of the Air Act or Water Act and related regulations. “Facility, “ as used in this clause means any building, plant, installation, structure, mine, vessel or other floating craft, location, or site of operations, owned, leased, or supervised by a contractor or subcontractor, used in the performance of a contract or subcontract. When a location or site of operations includes more than one building, plant, installation, or structure, the entire location or site shall be deemed a facility except when the administrator, or a designee, of the Environmental Protection Agency, determines that independent facilities are collocated in one geographical area. “Water Act.” As used in this clause, means Clean Water Act (33 USC 1251 et seq.).

(b) The contractor agrees--

1. To comply with all the requirements of section 114 of the Clean Air Act (42 USC 7414) and section 308 of the Clean Water Act (33 USC 1318 ) relating to inspection, monitoring, entry, reports, and information, as well as other requirements specified in section 114 and section 308 of the Air Act and Water Act, and all regulations and guidelines issued to implement those acts before the award of this contract;

2. That no portion of the work re1ored by this prime contract will be performed in a facility listed on the Environmental Protection Agency List of Violating Facilities on the date when this contract was awarded unless and until the EPA eliminates the name of the facility from the listing;

3. To use best efforts to comply with clean air standards and clean water standards at the facility in which the contract is being performed; and

4. To insert the substance of this clause into any nonexempt subcontract,

including this subparagraph (b)(4). - History: Rule 5-84, eff 11 Jul 84, (part).

APPENDIX I

EXAMINATION

The contractor agrees that the contracting officer, the Comptroller General of the United States, or the Secretary of the, Interior, or any of their duly authorized agents or representatives, shall, until the expiration of three years after final payment under this contract have access to and the right to examine any directly pertinent books, documents papers and records of the contractor involving transaction related to the contract. The contractor further agrees to include in all his subcontracts hereunder a provision to the effect that the subcontractor agrees that the contracting officer, the Comptroller General of the United States, or the Secretary of the Interior, or any of their duly authorized agents or

representatives, shall, until the expiration of three ears after final payment under the subcontract have access to and the right to examine any directly pertinent book, documents, papers and records of such subcontractor, involving transactions related to this contract.

APPENDIX J

PATENTS

The contractor shall hold and save the government and its officers, agents, servant, and employees harmless from liability of any nature or kind including cost and expenses for, or on account of, any patented or un-patented process, article, or appliance manufacture or used in the performance of the contract, including its used by the government, unless otherwise specifically stipulated in the contract documents. License and/or royalty fees for the use of a process which is authorized by the government on the project must be reasonable and paid to holder of the patent or his authorized licensee directly by the government and not by or through the contractor. If the contractor uses any design, device, or materials covered by letters for patent or copyright, he shall provide for such use by suitable agreement with the owner of such patented or copyright design, device or material. It is mutually agreed and understood, that, without exception, the contract prices shall include all royalties or costs arising shall from the use of such design, device, or material, in any way involved in the work. The contractor and/or his sureties shall indemnify and save harmless the government from any and all claims for infringement, by reason of the use of such patented or copyrighted design, device, or materials or any trademark or copyright in connection with work agreed to be performed under this contract, and shall indemnify the government for any cost, expense or damage which it may be obligated to pay by reason of such infringement at any time during the work or after completion of the work.- History: Rule 5-84, eff 11 Jul 84, (part).